Terms & Conditions

Last Updated: October 9, 2024

Welcome to RAJSHREE CORPORATION. These Terms and Conditions ("Terms") govern your use of our website and services. By accessing our website or engaging our services, you agree to be bound by these Terms.

1. Acceptance of Terms

By accessing and using the RAJSHREE CORPORATION website or services, you accept and agree to be bound by the terms and provision of this agreement. If you do not agree to abide by the above, please do not use this service.

2. Company Information

3. Services Description

RAJSHREE CORPORATION provides comprehensive IT services including but not limited to:

• Custom software development
• Web application development
• Mobile application development
• Cloud computing and DevOps services
• UI/UX design services
• IT consulting and strategy
• System integration and maintenance

4. Website Usage Terms

4.1 Permitted Use

You may use our website for lawful purposes only. You agree not to use the website:

• In any way that violates applicable laws or regulations
• To transmit or procure sending of any advertising or promotional material without our consent
• To impersonate or attempt to impersonate the company, employees, or other users
• To engage in any other conduct that restricts or inhibits anyone's use of the website

4.2 Intellectual Property

The content on this website, including text, graphics, logos, images, and software, is the property of RAJSHREE CORPORATION and is protected by copyright and other intellectual property laws. You may not reproduce, distribute, or create derivative works without our written permission.

5. Service Agreements

5.1 Project Engagement

Specific terms for software development projects will be outlined in separate service agreements or statements of work. These Terms serve as the general framework for all engagements with RAJSHREE CORPORATION.

5.2 Project Scope and Changes

• Project scope will be clearly defined in the service agreement
• Changes to project scope may result in additional costs and timeline adjustments
• All scope changes must be approved in writing by both parties
• RAJSHREE will provide estimates for additional work before implementation

5.3 Timeline and Deliverables

• Project timelines are estimates based on the agreed scope and requirements
• Delays caused by client feedback, approvals, or scope changes may affect delivery dates
• RAJSHREE CORPORATION will communicate any potential delays promptly
• Deliverables will be provided according to the agreed schedule and milestones

6. Payment Terms

6.1 Pricing and Invoicing

• All prices are quoted in Indian Rupees (INR) unless otherwise specified
• Payment terms will be specified in the service agreement
• Invoices are typically sent according to project milestones or monthly cycles
• Late payment may result in project suspension and additional charges

6.2 Taxes and Additional Costs

• All prices are exclusive of applicable taxes unless stated otherwise
• Client is responsible for any third-party costs (hosting, licenses, etc.) unless included in the agreement
• Currency conversion charges, if applicable, are the client's responsibility

7. Intellectual Property Rights

7.1 Client-Owned IP

Upon full payment, clients will own the intellectual property rights to custom-developed software, subject to the following:

• Exclusion of RAJSHREE proprietary tools, frameworks, and methodologies
• Third-party components remain subject to their respective licenses
• Source code ownership transfer upon final payment completion

7.2 RAJSHREE-Owned IP

RAJSHREE CORPORATION retains ownership of:

• Proprietary development tools and frameworks
• General methodologies and best practices
• Pre-existing intellectual property
• Knowledge and experience gained during the project

8. Confidentiality

RAJSHREE CORPORATION agrees to maintain the confidentiality of all client information and will:

• Not disclose confidential information to third parties without consent
• Use confidential information solely for project delivery purposes
• Implement appropriate security measures to protect sensitive data
• Return or destroy confidential information upon project completion

9. Warranties and Disclaimers

9.1 Service Warranties

RAJSHREE warrants that:

• Services will be performed with professional skill and care
• Deliverables will conform to agreed specifications
• We have the right to provide the agreed services
• Services will comply with applicable laws and regulations

9.2 Disclaimers

Except as expressly stated, RAJSHREE CORPORATION makes no warranties and disclaims all implied warranties including:

• Merchantability and fitness for a particular purpose
• Non-infringement of third-party rights
• Uninterrupted or error-free operation
• Compatibility with all systems and platforms

10. Limitation of Liability

To the maximum extent permitted by law, RAJSHREE CORPORATION's liability is limited as follows:

• Total liability shall not exceed the amount paid for the specific service
• We are not liable for indirect, incidental, or consequential damages
• We are not responsible for loss of profits, data, or business interruption
• Liability limitations apply regardless of the form of action

11. Indemnification

Client agrees to indemnify and hold RAJSHREE CORPORATION harmless from claims arising from:

• Client's use of deliverables in violation of agreements
• Client-provided content, data, or materials
• Modifications made by parties other than RAJSHREE
• Integration with third-party systems not approved by RAJSHREE

12. Termination

12.1 Termination Rights

Either party may terminate the agreement:

• For material breach with 30 days written notice to cure
• For convenience with 30 days written notice
• Immediately for insolvency or bankruptcy
• For violation of confidentiality or intellectual property terms

12.2 Effects of Termination

• Client remains liable for all work completed and expenses incurred
• RAJSHREE will deliver completed work upon payment
• Confidentiality obligations survive termination
• Both parties will return confidential information

13. Support and Maintenance

Post-delivery support terms:

• Bug fixes during warranty period (typically 30-90 days)
• Ongoing maintenance available under separate agreements
• Support response times as specified in service agreements
• Additional support services available at standard rates

14. Force Majeure

RAJSHREE CORPORATION is not liable for delays or failures due to circumstances beyond our reasonable control, including:

• Natural disasters, pandemics, or government actions
• Internet or telecommunications failures
• Third-party service provider outages
• Labor disputes or supply chain disruptions

15. Governing Law and Jurisdiction

These Terms are governed by the laws of India and the state of Gujarat. Any disputes shall be subject to the exclusive jurisdiction of the courts in Surat, Gujarat, India.

16. Dispute Resolution

In case of disputes, the parties agree to:

• First attempt resolution through good faith negotiations
• Consider mediation before pursuing litigation
• Submit to arbitration if mutually agreed
• Resolve disputes in English language

17. Modifications to Terms

RAJSHREE CORPORATION reserves the right to modify these Terms at any time. We will:

• Post updated Terms on our website
• Notify clients of material changes via email
• Provide reasonable notice before changes take effect
• Consider existing agreements under their original terms

18. Severability

If any provision of these Terms is found to be unenforceable, the remaining provisions will continue in full force and effect. The unenforceable provision will be replaced with an enforceable provision that most closely reflects the original intent.

19. Entire Agreement

These Terms, together with any service agreements and statements of work, constitute the entire agreement between the parties and supersede all prior negotiations, representations, or agreements relating to the subject matter.

20. Contact Information

For questions about these Terms or our services, please contact:

21. Acknowledgment

By using our website or engaging our services, you acknowledge that you have read, understood, and agree to be bound by these Terms and Conditions. If you do not agree with any part of these Terms, please do not use our services.